Have a personal or library account? Click to login
The structural equation model of risk factors influencing government irrigation project Cover

The structural equation model of risk factors influencing government irrigation project

Open Access
|Aug 2025

Full Article

1
Introduction

The construction industry is characterised by its distinctiveness, complexity, and differentiation from other sectors. It operates under a multitude of challenging conditions, including outdoor work environments, strict project deadlines, and unpredictable weather conditions (Pétursson 2015; Suárez et al. 2021). Furthermore, the involvement of diverse stakeholders such as project owners, architects, construction project supervisors, and contractors, each with specific roles and responsibilities (Osei-Asibey et al. 2021), creates a dynamic that is prone to conflicts and disputes (Kilag et al. 2024). These factors collectively contribute to the high-risk nature of the industry in terms of potential disagreements and legal challenges.

A construction project has a clear scope of operations as defined by the agreement and conditions of stakeholders (Jaffar et al. 2011; PMI 2013; San 2013; Pétursson 2015). The success of a construction project relies on effective cost management, time management, and quality management. Additionally, risk analysis is a critical knowledge area in construction management, influencing both time and cost of a project. Furthermore, conflicts within a project are also considered risk factors that can impact project outcomes. To mitigate such risks, appropriate conflict management tools are utilised to analyse and address risks in construction projects (Ghorbani 2023).

The researchers have noted that construction projects have two distinctive phases: the preconstruction phase (starting with project initiation, feasibility studies, and engineering design through the awarding of works contracts) and the construction phase (from awarding of works contracts to handing over completed works to the client). They observed that delays and cost overruns occurred in both phases but noted that project overruns were more frequent in the construction phase (Frimpong et al. 2003; Suárez et al. 2021). On the contrary, they have identified challenges in project construction such as extended construction times, loss of both capital and revenue, increasing market risk, material costs, delays in production, and low efficiency. The timely completion of a project means more profit, growth in the market, increased client trust, and increased stakeholder confidence. Due to the above facts, Shubham (2013) recorded that irrigation construction projects are commonly undertaken by government agencies because they are of national interest.

Currently, risk factors in construction projects are being studied to facilitate their identification and mitigation. The top five risk factors affecting project duration, ranked based on their relative importance index, are (1) inadequate project management, (2) delayed funding, (3) rework due to errors, (4) late material delivery and (5) shortages of skilled labour. In terms of cost, the top five risk factors include (1) rework due to errors, (2) underestimation of project completion time, (3) poor site management, (4) underestimation of project costs and (5) fluctuations in material prices. Regarding quality, the most significant risk factors are poor supervision, defective materials supplied by vendors, lack of consultant experience, unclear quality definitions and low bidding practices. Additionally, financial risks, particularly inflation in construction material prices, pose a major challenge to the construction industry, as highlighted in studies by Kamal et al. (2022) and Shibani et al. (2024).

To enhance knowledge of conflict management in construction projects, this study focuses on developing a structural equation model (SEM) of conflict management that affects a construction project. Furthermore, the model aims to improve the ability of project administration, especially in budget and time management. After all, this can be a guideline in construction management development everywhere.

2
Materials and methods
2.1
Construction project management

Project management is the application of knowledge, skills, tools and various techniques to process project activities. Furthermore, to succeed in the proposal of a project, there are 10 pieces of project management knowledge. The 10-project management knowledge has consistent data integration, and project cost management is one important process. In addition, project cost management consists of four processes: cost management planning, cost estimation, budgeting and cost control. In planning such a working process, it requires well-prepared and well-managed cost management of a project, together with project scope and execution strategy development, schedule planning and development, quality planning, resource planning, risk management, procurement planning and stakeholder planning (Hollmann 2006; Al Shami 2018).

2.2
Risk management

Project managers will recognise the classic systems methodology of input, process, output and feedback loop outlined above, which is vital to the effective control of a project; however, the risk is somehow different. It has to do with uncertainty, probability or unpredictability, and contingency planning according to the project management body of knowledge (PMBOK). Additionally, a project manager must be managing various risks, from the less complicated to the most complicated. Conflicts are common in construction projects. When each party has different motivations, attitudes, and opinions, it is possible to have conflicts. Therefore, project management must fix the problem as soon as possible; otherwise, other issues, such as an employee’s absence or resignation, may occur (Burke 2013). Risk management can reduce adverse effects in four ways: avoid, transfer, mitigate and accept (Lester 2007).

2.3
Irrigation construction projects

Irrigation is one of the crucial inputs to agricultural production, raising crop yields and increasing crop varieties in the region. The construction of irrigation schemes has also contributed to an increase in crop variety in the region. In consequence, the economic wellbeing of rural people is increased, and migration to big cities decreases. The overall level of spending on water-related infrastructure in developing countries amounts to about US$65 billion per year, with irrigation and drainage accounting for about US$25 billion (Briscoe 1999). The first irrigation scheme in Turkey was built in the Konya Plain by the Ottoman Empire between 1903 and 1913. Large-scale construction of irrigation and drainage schemes started with the foundation law numbered 6200 of the General Directorate of State Hydraulic Works (DSI). Classical open-channel irrigation schemes were built until 1950–1965. Since then, Western countries, especially Italy, have applied the flume (canalette), which is a type of prefabricated material. Sloped terrain requires a considerable number of drop-type constructions, needs to overcome water distribution problems during the operation phase, and needs close examination of low-pressure pipe schemes. In the 1980s, low-pressure concrete pipes were used. However, population growth in Turkey, together with the increase in rural to urban migration, brought an increase in water demand. As a result, in Turkey, since 1990, developing pipe production and water-saving tube technology, which allow usage of the optimum level of water resources, has started in high-pressure pipe schemes and sprinkler systems (Koç 2011).

Irrigation construction projects play a critical role in agricultural development by building infrastructure such as dams, canals, reservoirs and pipelines to manage and distribute water effectively. These projects are especially important in regions with inadequate rainfall, helping to enhance agricultural productivity, ensure food security, and support local economies. Additionally, irrigation projects are among the top three budget priorities in Thailand’s construction sector, as defined by the government. This prioritisation is due to the country’s predominantly agricultural economy, where a significant portion of the population consists of farmers. Additionally, most irrigation projects aim to mitigate flood risks and improve drainage infrastructure, which are critical concerns in Thailand. However, they often face significant challenges due to various risk factors that can disrupt progress and inflate costs (Abdaljader and Günal 2024).

Management-related risks are among the most impactful, including poor project planning, ineffective communication among stakeholders and delays in decision-making. These issues can lead to misaligned objectives and prolonged timelines. Financial risks are another critical concern, often stemming from budget constraints, delayed payments or inaccurate cost estimations, which can hinder progress and strain project resources. Material-related risks, such as shortages, delivery delays, and the use of substandard supplies, further exacerbate challenges during construction (Bahamid et al. 2020; Abdaljader and Günal 2024).

Labour and equipment issues also pose considerable risks. These include shortages of skilled workers, low productivity and equipment breakdowns or inefficiencies, all of which can disrupt workflows. Design risks, such as incomplete or unclear project plans, frequent changes or insufficient surveys conducted before construction, can lead to rework and delays. External risks, including adverse weather conditions, regulatory hurdles and shifts in government policies, add further complexity to these large-scale projects (McDermot et al. 2022; Abdaljader and Günal 2024).

Mitigating these risks requires comprehensive planning and effective collaboration among all stakeholders, including clients, contractors and consultants. This involves clear communication, accurate cost and resource estimations, timely procurement of materials, and robust risk assessment processes. By addressing these challenges proactively, irrigation construction projects can achieve their objectives, delivering sustainable water management solutions that benefit agriculture and local communities. Effective risk management is essential to ensuring that these projects are completed on time, within budget, and to the required standards (Abdaljader and Günal 2024; Adedokun and Egbelakin 2024).

2.4
Risk factors for construction project

An overview of risk factors in construction projects reveals several key issues identified in previous studies that stakeholders should be aware of. Many studies have categorised the group of risk factors that affect construction projects such as grouping of environmental, physical, logistic, legal, political, construction, design, financial and management (Bahamid et al. 2020). In the other hand, several researchers define eight components of risk factors: cost, construction knowledge, design, economic, estimator, resource, geographic and project-related (Ekung et al. 2021). Specifically in irrigation projects, five groups of risk factors identified through a relative importance index analysis include management, design, finance, materials, labor and equipment, and external factors.

Construction risk is the umbrella term for all possible losses that could occur during a construction project. Construction risk can be caused by various factors, including the environment, project delays, safety concerns and other challenges. Throughout the entire building process, risk is an unavoidable component, according to the PMBOK. Table 1 lists the 56 criteria that were compiled from the literature evaluation process and used in this investigation. Many risk factors are used in this study, and they focus only on risk factors that relate to construction projects, infrastructure projects and irrigation projects.

Tab. 1:

Risk factors at a sublevel that affect the construction of an irrigation project

Risk ID.DescriptiveReference
I1Delays caused by the approval – details of the construction plan (Shop drawing) of the employersE, T, O, Q, S
I2Delay factors caused by the approval-material of the employersE, T, O, S
I3Lack of a good coordination system between parties involved with each otherF, T, O, S, P
I4The factor of the employer planning the construction project is not detailed (not clear)G, T, Q, S
I5Mistakes against employer’s strike orderH, R, T
I6The contractor lacks knowledge and experience in construction techniquesF, T, S, P
I7The contractor does not pay attention to construction safetyI, T, Q, P
I8Accidents caused by the contractor’s construction, such as falls from heights, impacts, etc.I, Q, S, P
I9The employers lack control and inspection of the income-expensing accounting system of the construction projectJ, Q, S, P
I10Delays in recognising and solving problems between the individuals involvedJ, O, S
I11Mistake of communicationF, T, O, Q
I12The contractor breaches the terms of the contractJ, O, P
I13The text of the contract is unclear in terms of meaning, responsibility, or contract detailsJ, Q
I14Continuity in construction workF, R, O, P
I15Availability of labour in terms of number and skill.J, O, P
I16Coordination between parties involved in the projectF, Q, P
I17Project management and site supervisionF, R, S
I18Financial liquidity of construction projectsJ, R, S, P
I19Period for disbursing money from project owners and contractorsJ, Q, S, P
I20Accuracy and suitability of design dataJ, Q, S
I21The perfection of the design and the details of the design.K, Q, S
I22Project planning and budgetingJ, R, O, Q
I23Delivery of the construction siteJ, R, O, Q
I24Competence and compliance of subcontractorsJ, S, P
I25Personnel competenceL, T, S
I26Personnel commitmentL, T, P
I27Communication and coordinationJ, Q, S, P
I28Financial managementJ, R, O, P
I29Surveillance and monitoring of performanceJ, P
I30Late approval of the construction of drawings (Shop Drawing)J, T, O
I31The delay from the owner of the project in answering questions from the contractorJ, S
I32Installation payments are not as scheduledJ, R, Q, S, P
I33Deficiencies and unclear construction contractsJ, R, Q, S, P
I34Details of designs used in constructionK, Q, S, P
I35Interference with the contractor from the ownerJ, Q
I36Interfering with the contractor’s work by other contractors or other owners.J, S
I37Lack of expertise in the work of supervisorsF, O, S, P
I38The number of supervisors is insufficientJ, S
I39Supervisors have multiple chains of command, resulting in delayed decision-makingJ, T, S
I40Failure to take ownership of the construction site and the use of rights on route to the construction siteJ, T
I41Discovery of antiquities or ancient civilisation sites in construction sitesJ, S
I42Obstruction of buildings, restricted trees and utilities of other agenciesJ
I43The problem of working space conditions has changed from the counterparty contract modelJ, R, S
I44Problems with the condition of the work site. Hard stones are obstructed, causing the need to use tools. special in destructionJ, S
I45The delay in submitting the construction drawing (Shop Drawing) is delayedJ, R, Q, S
I46The delay in submitting construction drawings (As build Drawing) is delayedE, R, Q
I47the lack of experience of personnel and expertise in operations or construction planningJ, R, Q, S, P
I48Delays caused by subcontractor workE, T, P
I49The building does not comply with the contract without matching the specifications or construction drawingsJ, Q
I50Failure to comply with the request of the owner of the work that the contractor has agreed to according to that requestJ, Q, S
I51Deficiencies in tracking tasks and adjusting work plansJ, Q, S
I52Disorders in coordination on siteN, U, Q, S
I53Lack of management and coordination within the contractor’s organisationJ, T, O, P
I54Delay in procurement of equipment or construction materialsJ, T, Q, S, P
I55Using construction tools or equipment that do not meet the requirementsH, T, Q, S, P
I56Lack of financial liquidity of contractorsM, O, S
Y1DurationD
Y2BudgetD
Y3QualityD
2.5
Conceptual framework

The conceptual framework in this study is a structural framework built from the relationship between risk factors affecting cost management, time management and quality management. The factors will be analysed before developing the structural model that could be identified by exploratory factor analysis, as shown in Figure 1. With assumption 1 (H1), the risk factors affecting construction irrigation project management are related to three main aspects of project management.

Fig. 1:

Conceptual framework in this study.

3
Research methodology

The study of the conditions of the contract for architects and supervisors in the government construction project is quantitative research. The process of this study is divided into the following steps.

3.1
Population and sample

Since the entire population of the irrigation work group in Thailand is unknown, Cochran’s formula was used, calculated at a confidence level of 95%, a tolerance of 5%, and a proportion of the characteristic of interest in the population of 0.5. The required population size was 384 units (Burrows 1953), and the researcher allowed 50% (Chaitongrat et al. 2021), totalling 576 units in determining the sample size, which is consistent with the concept of Pallant (2020) that specified the acceptable size to be more than 150 samples and 460 responses and complete sets, which is a small proportion because most construction companies are not convenient to provide information. The response rate of the questionnaire (Respond Rate) of more than 20% is considered acceptable (Ehrlinger and Wöß 2022).

The sample for this research comprised 460 irrigation construction projects funded by government departments, classified as a type of public construction project under the Government Procurement and Supplies Management Act B.E. 2560 (2017), within the 2024 fiscal year. In addition, the representatives of each construction project were engineers who were experienced in construction management and supervision.

3.2
Research instrument

A questionnaire was used as a tool in the research. In addition, the questionnaire was divided into two parts: (1) participants’ general information and (2) issues about problems and conditions of the contract for architects and construction supervisors. Both parts were a closed-end questionnaire with five rating scales to evaluate the chance of having risk factors. Moreover, the research instrument employed in this study underwent rigorous validity and reliability testing to ensure its effectiveness. The validity test was conducted by three experts in construction management and government project supervision, following the methodology described by Kangpheng et al. (2016). As a result, this process identified and refined the final set of 56 factors used in the study. Additionally, the instrument’s reliability was evaluated through a try-out method involving 30 individuals who possessed similar characteristics to the sample population but were not included in the actual sample group. The tool achieved a Cronbach’s α value of 0.95, which significantly exceeds the standard reliability threshold of 0.75, as outlined by Vorakitkasemsakul (2011). Consequently, the questionnaire was deemed both valid and reliable, making it suitable for data collection from the study’s target sample.

3.3
Data analysis
3.3.1
Exploratory factor analysis

Factor analysis was employed to group the risk factors that contribute to construction project failure. Two indicators were used to validate the results: the Kaiser–Meyer– Olkin (KMO) measure of sampling adequacy and Bartlett’s test of sphericity (Thorndike, 1936; Ostle, 1963).

3.3.2
SEM

Computer packages SPSS25 and AMOS2 were used to assess the concordance between the model and empirical information by considering statistical chi-square, adjusted goodness of fit index (AGFI) and root mean square residual (RMR). Data analysis was divided into two phases: (1) results of information analysis correlation between factors and (2) results of relation conflict management in the government construction project fit of the model as per seven assessment criteria, which consisted of p-value or χ2, χ2/df, normal fit index (NFI), goodness of fit index (GFI), fit index (CFI), standardised RMR and root mean square error of approximation (RMSEA) (Pallant 2020).

4
Results and discussion

This research has investigated the relationship between risk factors that affect construction irrigation project management by analysing and building a structural model. In addition, the results of this study have been divided into three parts: general information about participants, exploratory factor analysis and the results of building the structural model of conflict management.

4.1
General information of participants

The analysis of the general data from the questionnaire and the evaluation of the research instruments revealed that the sample group comprised 70.87% male and 29.13% female participants. Most respondents were aged between 31 years and 50 years (48.48%), followed by those <30 years (38.91%) and >50 years (12.61%). In terms of educational background, the largest proportion held a bachelor’s degree (42.83%), while 36.74% had completed a higher vocational certificate, 17.39% had a vocational certificate, and 3.04% held a master’s degree or higher.

Regarding work experience, 32.39% of respondents had <5 years of experience, 30.65% had 5–10 years, 31.52% had 11–30 years, and 5.43% had >30 years of experience. Most participants worked in the private sector (74.13%), while 25.87% were employed in government organisations. In terms of job position, 26.30% of respondents were engineers, 11.52% were officers, and 6.30% were managers. A significant portion, 51.96%, held other roles such as supervisors or subcontractors, while 3.91% were directors, as summarised in Table 2.

Tab. 2:

Overview of participant

CategoryComponentAmountPercentage (%)
SexMale32670.87
Female13529.13
Age (years)<3017938.91
31–5022348.48
>505812.61
EducationVocational8017.39
Higher vocational16936.74
Bachelor19742.83
Master or higher143.04
Experience (years)<514932.39
5–1014130.65
11–3014531.52
>30255.43
OrganisationGovernment11925.87
Private company34174.13
PositionDirector183.91
Engineer12126.30
Manager296.30
Officer5311.52
Other (supervisor or subcontractor)23951.96

One limitation of this study is the private-sector sample bias, with 74.13% of the respondents representing private construction firms. This skewed distribution is primarily because private-sector organisations typically employ a larger workforce in construction projects compared with government agencies. In many construction projects, private-sector firms handle on-site management, subcontracting and execution, which require a higher number of personnel than governmental bodies that focus more on regulatory oversight and funding allocation (Ekung et al. 2021). Consequently, the findings of this study may not be fully generalised to government-led projects, where administrative and bureaucratic challenges may differ. Future research should incorporate a more balanced sample, ensuring greater representation from government stakeholders to provide a more comprehensive perspective on risk factors in construction projects. The mean and standard deviation values for each factor are presented in Table 3.

Tab. 3:

Mean and SD of risk factors

Risk ID.MeanSD
I13.330.90
I23.440.91
I33.080.71
I43.481.02
I53.381.07
I63.300.95
I73.351.11
I83.211.29
I93.130.97
I103.120.86
I113.280.96
I123.371.05
I133.150.87
I143.330.91
I152.850.95
I162.900.87
I172.831.05
I182.831.04
I192.952.27
I202.690.99
I212.751.09
I222.771.04
I232.830.97
I243.070.91
I252.761.07
I262.811.01
I272.821.02
I282.801.14
I292.841.16
I303.370.99
I313.130.82
I323.341.06
I333.300.95
I342.930.90
I353.181.02
I363.261.03
I373.340.91
I383.380.94
I393.500.98
I403.410.94
I413.291.70
I423.150.89
I433.250.77
I443.371.27
I453.190.96
I463.190.95
I473.260.94
I483.380.92
I493.300.99
I503.210.66
I513.220.96
I523.300.95
I533.221.07
I543.181.00
I553.131.08
I563.101.08
YI13.271.03
YI23.301.04
YI33.461.06

SD, standard deviation.

4.1.1
Exploratory factor analysis of risk factors in irrigation construction project

The results of the preliminary data screening indicated that all variables were normally distributed. Pearson correlation analysis was conducted for 12 variables, revealing a correlation coefficient of 0.77, which indicates a statistically significant positive relationship at the 0.01 level. This value falls within the acceptable range for correlation coefficients (0.3 to 0.9), as recommended by Amarasekara et al. (2018), as shown in Table 4.

Tab. 4:

KMO and Bartlett’s test

KMO measure of sampling adequacy0.943
Bartlett’s test of sphericityApprox. chi-square38,752.817
df1,540
Sig.0.001

KMO, Kaiser–Meyer–Olkin.

Findings from the examination of risk variables in the administration of construction projects—specifically in irrigation works—using principal component analysis (PCA), revealed that the correlation matrix obtained from Bartlett’s test of sphericity was statistically significant (p-value < 0.01), which meets the criterion of being less than 0.05. The Kaiser–Meyer–Olkin (KMO) measure of sampling adequacy was 0.943, indicating a very high value (close to 1), and suggesting that the dataset is well-suited for component analysis. The data significantly deviated from the identity matrix, confirming relationships among the 56 variables analyzed. Therefore, as shown in Table 5, the dataset is appropriate for factor extraction. The extracted components, as presented in Tables 5 to 7, were grouped into six categories: (1) inefficiency in legal administration, (2) inefficiency in project construction management, (3) inefficiency of contractors, (4) inefficiency in design during the construction phase, (5) discovery of antiquities at the construction site, and (6) conditions related to specialized work.

Tab. 5:

Number of components, eigenvalue, percentage of variance and percentage of cumulative variance

ComponentsInitial eigenvalues
Total% of varianceCumulative%
122.74740.62040.620
212.17621.74262.362
35.2259.33171.693
41.9103.41175.104
51.4622.61177.715
61.1041.97279.687
Tab. 6:

Factor loadings

Risk ID.Component
123456
I10.733
I20.586
I30.545
I40.800
I50.813
I60.870
I70.797
I80.678
I90.867
I100.749
I110.895
I120.901
I130.848
I140.791
I150.931
I160.835
I170.893
I180.840
I190.374
I200.882
I210.816
I220.889
I230.885
I240.568
I250.928
I260.936
I270.936
I280.888
I290.882
I300.742
I310.681
I320.592
I330.594
I340.587
I350.665
I360.762
I370.622
I380.626
I390.623
I400.655
I41
I420.627
I430.685
I44
I450.551
I460.580
I470.609
I480.630
I490.659
I500.635
I510.882
I520.869
I530.932
I540.879
I550.917
I560.874
Tab. 7:

Risk group

Risk group definingRisk factorsRisk ID.
1. The inefficiency of legal administrationDelay factors caused by the approval-material of the employersI2
Lack of a good coordination system between parties involved with each otherI3
The factors of the employees planning the construction project are not detailed (not clear)I4
Mistakes against employer’s strike orderI5
1. The inefficiency of legal administrationThe contractor lacks knowledge and experience in construction techniquesI6
The contractor does not pay attention to construction safetyI7
Accidents caused by the contractor’s construction, such as falls from heights and impactsI8
The employers lack control and inspection of the income-expense accounting system of the construction projectI9
delays in recognising and solving problems between the individuals involvedI10
Mistake of communicationI11
The contractor breaches the terms of the contract.I12
The text of the contract is unclear. both in terms of meaning, responsibility, contract detailsI13
Continuity in construction workI14
Instalment payments are not as scheduled.I32
Lack of expertise in the work of supervisorsI37
The number of supervisors is insufficientI38
Supervisors have multiple chains of command, resulting in delayed decision-makingI39
Failure to take ownership of the construction site and the use of rights on route to the construction siteI40
The problem of working space conditions has changed from the counterparty contract modelI43
Delays caused by subcontractor workI48
The building does not comply with the contract without matching the specifications or construction drawingsI49
Failure to comply with the request of the owner of the work that the contractor has agreed to according to that requestI50
2. The inefficiency of construction management in projectAvailability of labour in terms of number and skillI15
coordination between parties involved in the projectI16
2. The inefficiency of construction management in projectProject management and site supervisionI17
Financial liquidity of construction projectsI18
Period for disbursing money from project owners and contractorsI19
Accuracy and suitability of design dataI20
The perfection of the design and the details of the design.I21
Project planning and budgetingI22
delivery of the construction siteI23
Competence and Compliance of SubcontractorsI24
personnel competenceI25
personnel commitmentI26
communication and coordinationI27
financial managementI28
Surveillance and monitoring of performanceI29
details of designs used in constructionI34
3. The inefficiency of contractor in projectDelays caused by the approval – details of the construction plan (shop drawing) of the employersI1
Late approval of the construction drawings (shop drawing).I30
The delay from the owner of the project in answering questions from the contractor.I31
Deficiencies and unclear construction contractsI33
Disorders in coordination on siteI52
Lack of management and coordination within the contractor’s organisationI53
Delay in procurement of equipment or construction materialsI54
Using construction tools or equipment that do not meet the requirementsI55
Lack of financial liquidity of contractorsI56
4. The inefficiency of design in construction phaseThe delay in submitting the construction drawing (shop drawing) is delayedI45
The delay in submitting construction drawings (as build drawing) is delayedI46
the lack of experience of personnel and expertise in operations or construction planningI47
5. Discovery of antiquities at construction siteDiscovery of antiquities or ancient civilisation sites in construction sitesI41
6. The condition of special workProblems with the condition of the work site. Hard stones are obstructed, causing the need to use tools. special in destructionI44

The six groups were derived from the study by Abdaljader and Günal (2024) and other sources reviewed in the risk factors section. These defined groups are aligned with the Project Management Body of Knowledge (PMBOK) framework. The six identified groups of risk factors are critical to construction project management as they represent key areas that significantly influence project performance. The inefficiency of legal administration is crucial because delays in permits, contracts or legal disputes can disrupt timelines and budgets. The inefficiency of construction management in projects impacts coordination, resource allocation and schedule adherence, all of which are vital for project success. Similarly, the inefficiency of the contractor affects the quality of execution, adherence to deadlines and compliance with project specifications, making contractor performance a cornerstone of project outcomes. The inefficiency of design in the construction phase is another critical factor, as poor design can lead to costly rework, delays, and decreased structural integrity. The discovery of antiquities at the construction site introduces unexpected risks, including delays, additional costs for preservation efforts and legal implications, particularly for projects in historically significant areas. Finally, the condition of special work reflects unique challenges such as hazardous environments or specialised technical requirements, which necessitate careful planning and expertise to avoid accidents or inefficiencies. Together, these six factors represent interconnected risks that, if unmanaged, can escalate into significant obstacles. Addressing them systematically ensures smoother operations, controlled costs and adherence to project timelines, ultimately improving construction project outcomes (McDermot et al. 2022; Gajera 2024).

4.2
The results of building the structural model of risk factors in irrigation construction project

This study employs SEM to analyse the effects of 56 identified risk factors on three critical dependent variables: budget, duration and quality. SEM is a sophisticated statistical tool particularly suited for this research because it allows for the simultaneous examination of multiple dependent variables, enabling a holistic understanding of the complex interrelationships within construction projects. Additionally, SEM supports the integration of latent variables that are unobservable constructs such as ‘management effectiveness’ or ‘resource availability’, which are derived from measurable indicators. This feature enhances the depth of analysis by capturing nuanced aspects of risk dynamics. Moreover, SEM is capable of modelling both direct and indirect effects, providing insights into how risk factors influence project outcomes through intermediary pathways. Another significant advantage of SEM is its ability to account for measurement errors in the observed variables, thereby increasing the precision and reliability of the results. Through goodness-of-fit indices, SEM ensures that the theoretical model aligns with empirical data, reinforcing the validity of the findings. By leveraging these capabilities, this study provides a robust framework for identifying critical risk factors and their impacts, offering valuable insights for project managers to mitigate risks and enhance the success of construction projects.

The initial SEM shown in the Figure 2 highlights the hypothesised relationships among multiple risk factors, risk management and project outcomes (duration, budget and quality). Six primary risk factors were considered: inefficiency in legal administration, inefficiency in construction management, inefficiency of contractors, inefficiency of design in the construction phase, discovery of antiquities and special work conditions. These factors were expected to contribute to overall project risk, which influences risk management strategies and, subsequently, project outcomes.

Fig. 2:

Management structure model before the adjustment. GFI, goodness of fit index; NFI, normal fit index; RMR, root mean square residual; RMSEA, root mean square error of approximation.

The path coefficients reveal varying degrees of influence. Notably, inefficiency in legal administration exhibits the highest factor loading (1.00), indicating its significant contribution to overall project risk. By contrast, factors such as the discovery of antiquities and special work conditions show minimal impact, with factor loadings of 0.03 each. The influence of inefficiency in construction management is negative (–0.20), suggesting a counterintuitive relationship that may require further investigation. The pathways connecting risk management to project outcomes suggest a strong influence, with coefficients of 0.98, 1.02 and 1.00 for duration, budget and quality, respectively. However, the model’s fit indices indicate poor overall fit (GFI = 0.813, CFI = 0.864, RMSEA = 0.175), suggesting the need for refinement. High values for normed chi-square (15.024) and RMR (6.619) further indicate discrepancies between the hypothesised model and the observed data.

This initial model underscores the need for iterative adjustments to better align theoretical assumptions with empirical data and improve overall model fit.

The results of analysing the SEM of risk factors affecting irrigation construction projects have found that the initial model was inconsistent with the empirical data, making it impossible to draw conclusions and interpretations, as shown in Figure 2. In addition, there were the under-criteria statistical values, which were chi-square significant (p-value <0.05), relative chi-square value at 20.744 (higher than criteria), NFI value at 0.893 (lower than criteria), GFI value at 0.825 (lower than criteria), CFI value at 0.897 (lower than criteria), standardised RMR value at 0.024 (pass criteria) and RMSEA value at 0.243 (higher than criteria). This indicated that the initial model was inconsistent with the empirical data and needed to be adjusted. Later, the model was adjusted following the model modification indices (MI) value suggestion, and the results are shown in Figure 3. In addition, the statistical values were as follows: chi-square significant (p-value = 0.050), relative chi-square value at 0.212, NFI value at 0.996, GFI value at 0.990, CFI value at 0.999, standardised RMR value at 0.080 and RMSEA value at 0.030. These statistical values passed the criteria, indicating that the SEM of risk factors affecting irrigation construction projects was consistent with the empirical data, as shown in Figure 3. In addition, analysing the consistency and harmony of a measurement model for each latent variable to find the relation was demonstrated in Table 8. Considering the estimation of the parameters from regression analysis (R2), the result of analysing the structural equation found that the R2 value was 0.688, which means those factors can interpret the SEM.

Fig. 3:

Risk management structure model after the adjustment. AGFI, adjusted goodness of fit index; GFI, goodness of fit index; NFI, normal fit index; RMR, root mean square residual; RMSEA, root mean square error of approximation.

Tab. 8:

Index values of relations in SEM of risk management that affect the irrigation construction project before and after adjustment

IndexCriteriaBefore adjusting modelAfter adjusting model
StatisticResult of considerationStatisticResult of consideration
χ2/df<3.0015.024Unqualified0.413Qualified
p-value of χ2>0.05<0.001Unqualified0.799Qualified
NFI>0.900.864Unqualified0.999Qualified
GFI>0.900.856Unqualified0.999Qualified
CFI>0.950.856Qualified0.999Qualified
RMR<0.086.619Unqualified0.029Qualified
RMSEA<0.080.175Unqualified0.001Qualified

The p-value also sensitive to sample size >200.

GFI, goodness of fit index; NFI, normal fit index; RMR, root mean square residual; RMSEA, root mean square error of approximation; SEM, structural equation model.

To adjust the SEM following the model MI suggested value, the correlation was adjusted based on a review of the relevant literature and theories. Additionally, there were five relations among the variables that were adjusted as shown in Figure 3, which was the relation between the duration of construction projects and the condition of special work, such as when the construction contractor experiences a condition on the site that differs materially from the conditions indicated in the contract with the owner of the project or from what is normally expected in the site area. Almost all construction projects have risks. One of the major risks in construction projects arises when the contractor encounters a different site conditions (Srinavin et al. 2021). Moreover, this risk has been related to the inefficiency of legal administration and the discovery of antiquities at construction sites, which is crucial to construction project management according to the PMBOK. However, most countries try to apply several technologies to avoid risks that affect their projects. Several tools have been developed, such as machine learning and big data (Taylor and Littleton 2008).

The SEM highlights the relationships among identified risk factors, risk management and project outcomes (duration, budget and quality). The model reveals that risk factors such as inefficiency in legal administration, discovery of antiquities at construction sites and special work conditions impact overall project risk, which in turn influences the effectiveness of risk management strategies. Among these, inefficiency in legal administration is the most significant contributor, with a factor loading of 2.24, emphasising the critical need for streamlined legal processes to reduce delays and uncertainties. This is followed by the discovery of antiquities (factor loading 1.41), which underscores the importance of pre-construction assessments in historically significant areas, and special work conditions, which have the least impact (factor loading 0.05), although careful planning is still essential to mitigate minor risks. The model further demonstrates the direct impact of risk management on project outcomes. A path coefficient of 1.00 to project duration indicates that effective risk management plays a crucial role in avoiding delays, while a coefficient of 1.03 to budget highlights its importance in controlling costs. The slightly lower path coefficient of 0.98 to quality reflects that, while critical, risk management has a marginally lesser effect on ensuring project quality compared to cost or time. Overall, the relationships in the model signify that proactive and efficient risk management strategies are indispensable for mitigating the effects of project risks, particularly on financial and temporal outcomes. Additionally, the model stresses the relative importance of addressing legal inefficiencies, as they are the dominant risk factors, and tailoring risk management strategies to address specific high-priority risks effectively. The practical implications include prioritising legal and administrative process improvements, conducting thorough site assessments to identify archaeological risks early, and ensuring that risk management systems are integrated into project planning and execution phases. This approach not only minimises disruptions but also enhances the likelihood of achieving project goals in terms of duration, budget and quality. By understanding the varying influence of risk factors and leveraging efficient risk management, project teams can develop more targeted and effective strategies to ensure success. The SEM thus serves as a valuable tool for identifying critical areas of intervention and optimising project performance through structured risk management practices.

In construction project management, budget and quality are highly related to the status of projects, such as the high quality of work in construction, which should incur a lot of cost if the owner would like to perfect the building (Peterzens-Nysten 1998). This relationship has influenced the discovery of antiquities at construction sites, where remains of ancient civilizations have occasionally been uncovered (Ramaswamy, 2013). It has been studied that Egyptian antiquities are being protected using the dewatering technique. These tools are very expensive and require expertise in this technique. Moreover, some locations are very hard to find (Kusonkhum et al. 2023). When this situation happens in a construction project, it can result in significant costs. The prevention process will save their company, such as risk management (PMBOK), and some technologies will be used to predict the risk and feasibility of users or management, even though some of these tools cannot be applied for some reason in some countries.

Finally, risk management focuses on the time, cost and quality of projects. However, most irrigation projects are looking at soil moving work because they always build dams or canals to serve their people. Thus, the discovery of antiquities at construction sites and the condition of special work are very important in this case. Most of the population in this study proves that most firms in construction industries should be concerned about this result because it will decrease damage to the government and improve their construction management knowledge according to the PMBOK.

The SEM demonstrates the complex interrelationships among risk factors, risk management and project performance outcomes (duration, budget and quality) in construction projects. The model identifies three major risk factors: inefficiency in legal administration (1.00), discovery of antiquities at construction sites (0.03) and the condition of special work (0.03), all of which collectively influence overall risk exposure. Among these, legal inefficiency exerts the strongest impact on risk factors, indicating that bureaucratic obstacles, regulatory delays and contract disputes are dominant sources of uncertainty in construction projects. By contrast, the discovery of antiquities and specialised work conditions have a much smaller effect, suggesting that while these risks exist, their frequency and overall impact on construction projects are relatively low. These risk factors contribute to the overall risk environment, which directly affects risk management (0.06), implying that as risk factors increase, the need for structured risk management approaches becomes more critical. However, the small coefficient suggests that risk management effectiveness can mitigate the negative influence of these risk factors if implemented properly.

The model further demonstrates that risk management serves as a crucial intermediary variable, significantly influencing project outcomes. The strongest impact is observed on budget (1.03), followed by duration (1.00) and quality (0.98), which indicates that financial management is the most sensitive aspect of risk exposure in construction projects. This relationship suggests that poor risk management leads to budget overruns, while effective risk strategies can reduce cost escalations. The slightly lower coefficient for quality (0.98) implies that while risk management plays a critical role in maintaining project standards, other external factors, such as material quality and labour expertise, may also influence quality outcomes independently. Additionally, the interconnections between project performance variables reveal that budget and quality (0.01) are weakly correlated, meaning that cost fluctuations slightly impact quality but do not directly dictate project standards. The model also illustrates a feedback loop between risk factors and project outcomes, emphasising how legal inefficiency (2.24) and financial constraints (0.05) create reinforcing cycles of risk exposure, meaning that poor legal administration not only introduces risks but also exacerbates delays, budget issues and quality concerns over time.

The high model fit indices (chi-square = 1.652, p-value = 0.799, CFI = 1.000, GFI = 0.999, RMSEA = 0.000) confirm that the proposed relationships between variables are statistically significant and accurately reflect real-world project dynamics. These findings reinforce the need for proactive legal frameworks, robust risk assessment mechanisms and financial planning strategies to improve the efficiency of construction project. Future research should explore alternative risk variables, such as fluctuating material prices or labour shortages, and integrate qualitative insights through interviews or case studies to provide a more comprehensive understanding of how risk factors interact over time. Additionally, emerging technologies like machine learning and Internet of Things (IoT)-driven risk monitoring systems could be integrated into risk management frameworks to enhance predictive capabilities and improve real-time decision-making. Overall, this SEM highlights the intricate causal relationships among risk factors, management interventions and project outcomes, emphasising the necessity for a structured and data-driven approach to risk mitigation in construction projects.

4.3
Hypothesis and result
4.3.1
Hypotheses development

This study posits three main hypotheses to explore the relationships among risk factors, risk management and project outcomes in construction projects. H1 suggests that risk factors – such as inefficiency in legal administration, inefficiency in construction management, contractor inefficiency, design inefficiency, discovery of antiquities and special work conditions – significantly contribute to overall project risk. This assumption is grounded in the understanding that these factors collectively disrupt project timelines, budgets and quality. H2 hypothesises that these risk factors directly influence the effectiveness of risk management strategies, as effective management often depends on identifying and addressing key risks. Finally, H3 proposes that risk management practices positively impact project outcomes, with effective strategies expected to reduce delays, control costs and maintain quality. These hypotheses reflect the interconnected nature of risk factors, management practices and project performance, as established in the literature.

4.3.2
Hypothesis evaluation

Based on the results of the initial SEM, the findings partially support H1. The inefficiency in legal administration demonstrated the strongest factor loading (1.00), signifying its critical contribution to project risks. However, other factors, such as the discovery of antiquities and special work conditions, showed minimal contributions (0.03 each). Notably, inefficiency in construction management exhibited a negative relationship (–0.20), suggesting complexities that require further investigation. For H2, the weak path coefficient (0.06) between risk factors and risk management suggests a limited impact, indicating that risk management strategies might not fully account for or respond to specific risk factors. While this does not entirely reject H2, it highlights inefficiencies in translating identified risks into effective management practices.

4.3.3
Implications and acceptance

By contrast, H3 is strongly supported by the results. The path coefficients from risk management to project outcomes were significant, with 1.02 for budget, 0.98 for duration and 1.00 for quality. These findings underscore the importance of robust risk management strategies in ensuring project success, particularly in controlling costs and maintaining timelines. Collectively, the results suggest that while the contribution of specific risk factors to overall risk (H1) and their influence on risk management (H2) require further refinement and exploration, the role of risk management in achieving favourable project outcomes (H3) is unequivocal. These findings emphasise the need to prioritise effective legal administration and refine risk management strategies to address diverse risks more comprehensively, ultimately improving project performance. Further refinements of the SEM and additional data collection could provide deeper insights into these relationships.

5
Conclusion

This study underscores the critical role of risk management in construction irrigation projects by employing SEM to analyse key risk factors affecting project success. The findings highlight several significant insights that contribute to the field of construction risk management:

  • Identification of key risk factors: This study reveals that inefficiencies in legal administration, discovery of antiquities at construction sites and challenges associated with specialised work conditions are the most influential risk factors affecting project performance. Among these, legal inefficiencies exhibit the strongest effect, emphasising the need for streamlined regulatory processes to mitigate project delays and cost overruns.

  • Development of an enhanced SEM: The research demonstrates that the revised SEM achieves a superior fit with empirical data, confirming its robustness in assessing risk factors. The final model presents strong goodness-of-fit indices (GFI = 0.999, CFI = 0.999, RMSEA = 0.001), validating its reliability for application in construction project risk assessment.

  • Strategic implications for risk management: This study underscores the importance of proactive risk mitigation strategies, particularly in addressing bureaucratic inefficiencies and unforeseen site conditions. Implementing structured legal frameworks, enhancing stakeholder collaboration and integrating advanced risk management techniques can significantly reduce project uncertainties and improve overall efficiency.

These findings provide valuable guidance for policymakers, project managers and construction stakeholders in optimising risk management practices within government-funded irrigation projects. Future research should explore emerging technologies, such as artificial intelligence and predictive analytics, to further enhance risk assessment and mitigation strategies in large-scale infrastructure projects.

6
Future research and practical implications

Despite its contributions, this study has several limitations that future research should address. One significant challenge was data collection in Thailand, particularly due to limited collaboration with local government agencies. Many officials demonstrated low awareness of research methodologies and their potential societal benefits. For instance, identifying high-risk factors in construction projects could enable authorities to develop more proactive risk mitigation strategies, leading to reduced project delays and improved efficiency. Future research should explore methods to bridge this gap, such as stakeholder engagement programs that enhance awareness and promote the adoption of research-driven risk management practices.

Additionally, real-world observational research and experimental investigations are necessary to validate and expand upon these findings. Future studies could conduct longitudinal analyses of construction projects to track how risk factors evolve over time and how various risk mitigation strategies impact project outcomes. By addressing these limitations, future studies can contribute to more adaptive, efficient and sustainable construction risk management strategies, ultimately benefiting both the industry and society.

DOI: https://doi.org/10.2478/otmcj-2025-0010 | Journal eISSN: 1847-6228 | Journal ISSN: 1847-5450
Language: English
Page range: 154 - 170
Submitted on: Aug 28, 2024
Accepted on: Mar 6, 2025
Published on: Aug 12, 2025
Published by: Sciendo
In partnership with: Paradigm Publishing Services
Publication frequency: 1 times per year

© 2025 Anuchat Leeanansaksiri, Phongphan Tankasem, Wuttipong Kusonkhum, published by Sciendo
This work is licensed under the Creative Commons Attribution 4.0 License.